2025建筑工程施工合同（中英文對照版）ConstructionContractforBuildingEngineering2025(Chinese-EnglishVersion)本合同由以下雙方于年月日簽訂：ThisContractisenteredintobyandbetweenthefollowingpartiesonthedateofYearMonthDay:**甲方（發包方）:**PartyA(Contractor):名稱：地址：法定代表人：聯系XX：統一社會信用代碼：Name:Address:LegalRepresentative:ContactTelephone:UnifiedSocialCreditCode:乙方（承包方）:PartyB(Contractee):名稱：地址：法定代表人：聯系XX：統一社會信用代碼：Name:Address:LegalRepresentative:ContactTelephone:UnifiedSocialCreditCode:鑒于甲方將位于的建筑工程發包給乙方施工，為了明確雙方的權利和義務，根據《中華人民共和國合同法》及相關法律法規，雙方本著平等、自愿、公平的原則，經友好協商，達成如下協議：WhereasPartyAintendstoengagePartyBtocarryoutabuildingprojectlocatedatandtoclearlydefinetherightsandobligationsofbothparties,basedontheContractLawofthePeople'sRepublicofChinaandrelatedlawsandregulations,PartyAandPartyB,basedontheprincipleofequality,voluntariness,andfairness,haveagreeduponthefollowingtermsafterfriendlyconsultations:第一條工程概況Article1:ProjectOverview工程名稱:ProjectName:工程地點:ProjectLocation:工程內容:ProjectContent:工程規模:ProjectScale:總建筑面積：平方米TotalConstructionArea:SquareMeters工程范圍:ScopeofWork:第二條合同工期Article2:ContractDuration計劃開工日期:PlannedStartDate:年月日YearMonthDay計劃竣工日期:PlannedCompletionDate:年月日YearMonthDay總工期:TotalDuration:日歷天CalendarDays延期責任:LiabilityforDelays:由于乙方原因導致工期延誤，每延誤一天，乙方應向甲方支付合同總價的%作為違約金。AnydelaycausedbyPartyBshallresultinPartyBpayingPartyAapenaltyequalto%ofthetotalcontractpriceforeachdayofdelay.第三條合同價款Article3:ContractPrice合同總價:TotalContractPrice:人民幣（大寫）：元整RMB(inwords):YuanWhole付款方式:PaymentMethod:（1）工程預付款：合同總價的%，于合同簽訂后日內支付。AdvancePayment:%ofthetotalcontractprice,tobepaidwithindaysafterthesigningofthisContract.（2）工程進度款：按月進度支付，每月支付已完工程量的%。ProgressPayment:Paymentsaremademonthly,covering%ofthecompletedworkvolumeforthatmonth.（3）工程竣工款：工程竣工驗收合格后日內支付合同總價的%。CompletionPayment:%ofthetotalcontractpriceispaidwithindaysaftertheprojectpassesthefinalinspection.違約金:Penalty:任何一方未按合同約定支付款項的，每逾期一天，應向對方支付應付金額的%作為違約金。AnypartythatfailstomakepaymentasstipulatedinthisContractshallpaytheotherpartyapenaltyof%oftheamountdueforeachdayofdelay.第四條工程質量Article4:QualityoftheProject質量標準:QualityStandards:本工程執行《建筑工程施工質量驗收統一標準》GB50300-2013及國家和地方的相關標準。Thisprojectshallbecarriedoutinaccordancewiththe"UnifiedStandardforQualityAcceptanceofBuildingEngineeringConstruction"GB50300-2013,aswellasrelevantnationalandlocalstandards.質量驗收:QualityInspection:工程質量的驗收由甲方組織，乙方配合。驗收不合格的，乙方應在規定時間內返工或整改。QualityinspectionshallbeorganizedbyPartyAwiththecooperationofPartyB.Incaseofunsatisfactoryinspection,PartyBshallcarryoutreworkorrectificationwithinthespecifiedtime.質量保修:QualityWarranty:工程竣工驗收合格后，乙方提供年的質量保修期。Aftertheprojectpassesthefinalinspection,PartyBshallprovidea-yearwarrantyfortheproject.第五條安全責任Article5:SafetyResponsibility安全措施:SafetyMeasures:乙方應嚴格按照安全生產規定進行施工，確保施工人員和設備的安全。PartyBshallstrictlycomplywithsafetyproductionregulationsandensurethesafetyofworkersandequipment.保險:Insurance:乙方應為施工現場的員工和設備購買必要的保險。PartyBshallpurchasenecessaryinsuranceforitsstaffandequipmentontheconstructionsite.責任劃分:LiabilityAllocation:因乙方原因造成的安全事故，由乙方承擔全部責任。PartyBshallbearfullresponsibilityforanyaccidentscausedbyitsnegligence.第六條材料與設備Article6:MaterialsandEquipment材料采購:MaterialProcurement:工程所需材料由乙方負責采購，乙方采購的材料必須符合國家和行業標準。MaterialsrequiredfortheprojectshallbeprocuredbyPartyB,whichshallensurethatallmaterialscomplywithnationalandindustrystandards.設備管理:EquipmentManagement:施工期間，乙方應妥善管理施工設備，確保設備正常運行。Duringconstruction,PartyBshallproperlymanageconstructionequipmenttoensureitsnormaloperation.第七條驗收與移交Article7:AcceptanceandTransfer驗收標準:AcceptanceCriteria:工程驗收標準以本合同約定的工程質量標準為準。TheacceptancecriteriafortheprojectshallbebasedonthequalitystandardsstipulatedinthisContract.驗收程序:AcceptanceProcedures:驗收工作由甲方組織，乙方配合，驗收合格后雙方簽訂《工程驗收合格證明書》。AcceptanceshallbeorganizedbyPartyAwiththecooperationofPartyB,anduponsatisfactorycompletion,bothpartiesshallsignthe"CertificateofProjectAcceptance."工程移交:ProjectTransfer:工程驗收合格后日內，乙方將工程交付甲方使用。Withindaysaftersuccessfulacceptance,PartyBshalltransfertheprojecttoPartyAforuse.第八條保修責任Article8:WarrantyLiability保修期限:WarrantyPeriod:本工程保修期為年，自工程竣工驗收合格之日起計算。Thewarrantyperiodforthisprojectisyears,commencingfromthedateofsuccessfulfinalinspection.保修范圍:WarrantyScope:包括但不限于結構工程、防水工程、機電設備等。Includingbutnotlimitedtostructuralengineering,waterproofingengineering,andmechanicalandelectricalequipment.保修服務:WarrantyServices:在保修期內，乙方應及時響應甲方的保修請求。Withinthewarrantyperiod,PartyBshallpromptlyrespondtoPartyA'swarrantyrequests.第九條違約責任Article9:LiabilityforBreachofContract甲方違約:BreachbyPartyA:甲方未按合同約定支付款項的，每逾期一天，應向乙方支付應付金額的%作為違約金。AnydelaybyPartyAinmakingpaymentsasstipulatedinthisContractshallresultinPartyApayingPartyBapenaltyof%oftheamountdueforeachdayofdelay.乙方違約:BreachbyPartyB:（1）乙方未按合同約定工期完成工程的，每逾期一天，應向甲方支付合同總價的%作為違約金。DelayinCompletion:PartyBfailingtocompletetheprojectaspertheagreedscheduleshallpayPartyAapenaltyof%ofthetotalcontractpriceforeachdayofdelay.（2）乙方未按合同約定標準完成工程的，應負責返工直至符合標準，承擔返工費用。Non-compliancewithStandards:PartyBshallberesponsibleforrectifyingtheprojectuntilitmeetstherequiredstandardsandshallalsobearallcostsrelatedtosuchrectification.第十條爭議解決Article10:DisputeResolution本合同在履行過程中發生爭議的，雙方應友好協商解決；協商不成的，任何一方可向仲裁委員會申請仲裁，或直接向人民法院提起訴訟。IncaseofdisputesarisingfromtheperformanceofthisContract,thepartiesshallfirstseektoresolvethemthroughfriendlyconsultations.Ifconsultationsfailtoresolvethedisputes,