2025建筑工程施工合同-中英對照版正文本合同（以下簡稱“本合同”）由以下雙方于年月日在中華人民共和國（以下簡稱“中國”）市區簽訂：甲方：（以下簡稱“發包人”）地址：法定代表人：聯系方式：乙方：（以下簡稱“承包人”）地址：法定代表人：聯系方式：鑒于發包人擬將工程（以下簡稱“本工程”）發包給承包人施工，承包人同意接受本工程的施工任務。根據《中華人民共和國合同法》、《中華人民共和國建筑法》及相關法律法規，雙方本著平等、自愿、誠實信用的原則，達成如下協議：第一條工程概況1.1工程名稱：1.2工程地點：1.3工程內容：（詳細描述工程范圍及工作內容）1.4工程規模：1.5工程質量標準：（注：工程內容應詳細列明項目范圍，例如建筑、安裝、裝修等，確保雙方對工程范圍有清晰的共識。）第二條合同工期2.1開工日期：年月日2.2竣工日期：年月日2.3總工期：天2.4工期順延條款：因不可抗力、發包人原因或設計變更導致的停工，工期相應順延。順延天數由雙方協商確定，并簽訂書面補充協議。第三條合同價款及支付方式3.1合同總價：人民幣元（大寫：）3.2付款方式：第一期進度款：合同簽訂后日內，支付合同總價的%；第二期進度款：主體結構封頂后日內，支付合同總價的%；第三期進度款：工程竣工驗收合格后日內，支付合同總價的%；尾款：質保期滿后日內，支付剩余合同總價的%。3.3價格調整：因材料價格波動、政策性調整或設計變更導致的費用增加，雙方可協商簽訂補充協議調整合同價款。第四條工程質量及驗收標準4.1施工質量標準：符合國家及地方建筑工程質量標準；達到設計要求；符合施工規范。4.2驗收程序：隱蔽工程驗收：承包人應提前小時通知發包人進行隱蔽工程驗收，未經驗收不得進入下一道工序；竣工驗收：工程竣工后日內，承包人應向發包人提交完整的竣工資料，并配合發包人組織竣工驗收。4.3質量保修：質保期限：自工程竣工驗收合格之日起為年；質保范圍：包括但不限于（具體范圍）。第五條雙方權利與義務甲方（發包人）權利與義務：5.1發包人權利：監督工程進度及質量，提出合理建議；按時支付合同價款；及時提供施工圖紙及相關資料。5.2發包人義務：為承包人提供必要的施工條件；按約定支付工程進度款；及時辦理工程驗收及結算手續。乙方（承包人）權利與義務：5.3承包人權利：要求發包人按約定支付工程款；要求發包人提供必要的施工條件。5.4承包人義務：按照合同約定的工期、質量標準完成施工任務；嚴格遵守國家及地方建筑施工規范，確保施工安全；負責施工現場的管理及人員培訓。第六條違約責任6.1發包人違約責任：未按約定支付工程款，每逾期一日，按未支付金額的%支付違約金；因發包人原因導致工期延誤，工期相應順延，且發包人需承擔由此產生的額外費用。6.2承包人違約責任：未按約定工期完成工程，每逾期一日，按合同總價的%支付違約金；施工質量不符合約定標準，需返工或修復，由此產生的費用由承包人承擔。第七條安全施工責任7.1承包人應嚴格遵守國家及地方安全生產法律法規，確保施工安全。7.2因承包人原因導致的安全事故，由承包人承擔全部責任；因發包人原因導致的安全事故，由發包人承擔相應責任。第八條爭議解決8.1本合同履行過程中如發生爭議，雙方應友好協商解決。協商不成的，任何一方均可向工程所在地人民法院提起訴訟。第九條合同生效及其他9.1本合同經雙方簽字蓋章后生效。9.2本合同一式份，雙方各執份，具有同等法律效力。9.3本合同未盡事宜，雙方可簽訂補充協議，補充協議與本合同具有同等法律效力。甲方（蓋章）：法定代表人（簽字）：日期：年月日乙方（蓋章）：法定代表人（簽字）：日期：年月日附：英文對照版本（EnglishSupplementaryVersion）ThisConstructionContract(hereinafterreferredtoas"thisContract")isenteredintobyandbetweenthefollowingtwopartiesonday,month,year,inthePeople'sRepublicofChina,City,District:PartyA:(hereinafterreferredtoas"theEmployer")Address:LegalRepresentative:ContactInformation:PartyB:(hereinafterreferredtoas"theContractor")Address:LegalRepresentative:ContactInformation:ConsideringthattheEmployerintendstosubcontracttheProject(hereinafterreferredtoas"theProject")totheContractorforconstruction,andtheContractoragreestoaccepttheconstructiontaskoftheProject.Basedonthe"ContractLawofthePeople'sRepublicofChina,""ConstructionLawofthePeople'sRepublicofChina,"andrelevantlawsandregulations,bothpartieshereinagreeasfollows:Section1:ProjectOverview1.1ProjectName:1.2ProjectLocation:1.3ProjectContent:(Detaileddescriptionofprojectscopeandworkcontent)1.4ProjectScale:1.5QualityStandards:Section2:ContractDuration2.1StartDate:yearmonthday2.2CompletionDate:yearmonthday2.3TotalDuration:days2.4ExtensionofTime:Thecompletiontimemaybeextendedduetoforcemajeure,Employerreasons,ordesignchanges.Thenumberofextendeddaysshallbemutuallyagreeduponbybothpartiesandstipulatedinawrittensupplementaryagreement.Section3:ContractPriceandPaymentTerms3.1ContractTotalPrice:RMB(大寫:)3.2PaymentTerms:FirstProgressPayment:%ofthecontracttotalwithindaysafterthesigningofthisContract;SecondProgressPayment:%ofthecontracttotalwithindaysafterthetoppingoutofthemainstructure;ThirdProgressPayment:%ofthecontracttotalwithindaysafterthecompletionandacceptanceoftheProject;Retainage:%ofthecontracttotalwithindaysaftertheexpirationofthewarrantyperiod.Section4:ProjectQualityandAcceptanceCriteria4.1ConstructionQualityStandards:Complywithnationalandlocalbuildingconstructionqualitystandards;Meetthedesignrequirements;Adheretoconstructionspecifications.4.2AcceptanceProcedures:HiddenWorksInspection:TheContractorshallnotifytheEmployerhoursinadvancefor隱蔽工程驗收(hiddenworksinspection).Nosubsequent工序(procedures)shallcommencewithoutinspection;FinalAcceptance:WithindaysafterthecompletionoftheProject,theContractorshallsubmitcomplete竣工資料(竣工materials)totheEmployerandcooperatewiththeEmployertoorganizethefinalacceptance.4.3QualityWarranty:WarrantyPeriod:yearsfromthedateofsuccessfulcompletionandacceptanceoftheProject;WarrantyScope:Includingbutnotlimitedto(specificscope).Section5:RightsandObligationsofBothPartiesRightsandObligationsoftheEmployer(PartyA):5.1Employer'sRights:Monitorprojectprogressandquality,andmakereasonablesuggestions;Paythecontractpriceinaccordancewiththeagreement;Timelyprovide施工圖紙(constructiondrawings)andrelateddocuments.5.2Employer'sObligations:Providenecessary施工條件(constructionconditions)fortheContractor;TimelypaytheprogresspaymentsasstipulatedintheContract;Timelyhandleprojectacceptanceandsettlementprocedures.RightsandObligationsoftheContractor(PartyB):5.3Contractor'sRights:RequesttheEmployertopaytheprojectpaymentsinaccordancewiththeagreement;RequesttheEmployertoprovidenecessaryconstructionconditions.5.4Contractor'sObligations:Completetheconstructiontaskswithintheagreedtime,quality,andbudget;Strictlycomplywithnationalandlocalconstructionnormstoensure施工安全(constructionsafety);Beresponsibleforsitemanagementandstafftraining.Section6:LiabilityforBreachofContract6.1LiabilityoftheEmployer:IftheEmployerfailstopaythecontractpriceasagreed,a違約金(penalty)of%oftheoverdueamountperdayshallbepaid;IftheEmployercausesdelaysintheprojectduetotheirreasons,thecompletiontimeshallbeextendedaccordingly,andtheEmployershallbearalladditionalcostsincurred.6.2LiabilityoftheContractor:IftheContractorfailstocompletetheprojectasagreed,apenaltyof%ofthecontracttotalperdayshallbepaid;Iftheconstructionqualitydoesnotmeettheagreedstandards,theContractorshallberesponsibleforreworkorrepairsattheirownexpense.Section7:SafetyConstructionResponsibilities7.1TheContractorshallstrictlycomplywithnationalandlocalsafetyproductionlawsandregulationstoensure施工安全(constructionsafety).7.2IfaccidentsoccurduetotheContractor'sreasons,theContractorshallbearfullresponsibility;ifaccidentsoccurduetotheEmployer'sreasons,theEmployershallbearcorrespondingresponsibility.Section8:DisputeResolution8.1AnydisputesarisingfromtheperformanceofthisContractshallberesolvedthroughfriendlynegotiationsbybothparties.Ifnegotiationsfail,anypartymayfilealawsu